Terms and Conditions

---

TERMS AND CONDITIONS OF SERVICE

Please read these Terms and Conditions ("Terms") carefully before accessing or using the services provided by Wrightway Cabinets and Trim Inc. ("the Company"). By accessing or using our services, you agree to be bound by these Terms.

1. Acceptance of Terms

1.1 By accessing or using our services, you acknowledge that you have read, understood, and agree to be bound by these Terms.

2. Services

2.1 The Company provides professional designing and installation of cabinets, shelving, trim.

2.2 The specific details and scope of services will be agreed upon in writing between the Company and the client. Any changes to the agreed services must be documented and mutually agreed upon.

2.3 The Company will strive to provide high-quality services within the agreed timeframe. However, the Company does not guarantee specific results or completion dates, as unforeseen circumstances may arise during the project.

3. Payment Terms

3.1 The client shall pay the Company according to the agreed payment terms. Payment terms, including deposit requirements, progress payments, and final payment, will be outlined in the written agreement or proposal provided by the Company.

3.2 In the event of any delay or non-payment by the client, the Company reserves the right to suspend or terminate services until payment is received. Additional costs incurred due to such suspension or termination will be the client's responsibility.

4. Intellectual Property

4.1 All intellectual property rights, including designs, plans, drawings, and specifications, created or provided by the Company, shall remain the property of the Company, unless otherwise agreed in writing.

4.2 The client may use the Company's intellectual property solely for the purpose of the project for which it was provided. Any other use, reproduction, or distribution of the Company's intellectual property requires prior written consent from the Company.

5. Liability and Warranty

5.1 The Company shall perform its services with reasonable skill, care, and professionalism. However, the Company does not warrant or guarantee the accuracy, completeness, or suitability of its services for any particular purpose.

5.2 The Company shall not be liable for any direct, indirect, incidental, consequential, or exemplary damages arising out of or in connection with the services provided, including but not limited to delays, errors, defects, or loss of profits.

5.3 The Company shall not be held responsible for any damage, loss, or delay caused by third-party suppliers, contractors, or any circumstances beyond the Company's control.

6. Confidentiality

6.1 The Company and the client agree to keep any confidential information exchanged during the course of the project confidential and not disclose it to any third parties without prior written consent from the other party.

7. Termination

7.1 Either party may terminate the services by providing written notice to the other party. In the event of termination, the client shall compensate the Company for any completed work and expenses incurred up to the termination date.

8. Governing Law and Dispute Resolution

8.1 These Terms shall be governed by and construed in accordance with the laws of [Jurisdiction]. Any disputes arising from these Terms shall be subject to the exclusive jurisdiction of the courts in [Jurisdiction].

9. Entire Agreement

9.1 These Terms constitute the entire agreement between the Company and the client and supersede any prior agreements, whether written or oral, relating to the subject matter herein.

10. Amendments

10.1 Any amendments or modifications to these Terms must be in writing and signed by both parties.

11. Contact Us

11.1 If you have any questions or concerns regarding these Terms, please contact us at [contact information].

By accessing or using our services, you confirm that you have read and understood these Terms and agree to abide by them.